Effective Date: 15/10/2025
Website: https://dekowish.in
Company Name: Dekowish
1. Introduction
Welcome to Dekowish. By accessing or using our website dekowish.in, you agree to comply with and be bound by these Terms and Conditions.
If you do not agree to these terms, please do not use our website or services.
These Terms govern your use of our website, communication, and interior design services offered by Dekowish, a design firm based in Kolkata, West Bengal, India.
2. Use of Our Website
You agree to use dekowish.in only for lawful purposes and in a way that does not violate any applicable laws or regulations.
You must not:
- Attempt to gain unauthorized access to the website or its servers
- Copy, reproduce, or distribute any content without prior written consent
- Engage in any conduct that could damage, disable, or impair the website
3. Services Offered
Dekowish provides professional interior design, space planning, visualization, modular kitchen design, furniture fabrication, civil work, painting, lighting, and turnkey project solutions.
All services are subject to a project-based agreement, including quotations, timelines, and scope of work.
The website content, including images, project portfolios, or design concepts, is for informational and promotional purposes only and does not constitute a binding offer.
4. Project Terms and Payments
- All design and execution projects begin only after mutual agreement and confirmation through a written quotation or contract.
- Payments must be made according to the milestones or schedule mentioned in the quotation or project agreement.
- Delayed payments may result in suspension or postponement of work.
- Advance payments are non-refundable, as they cover design and consultation time, resource allocation, and initial project expenses.
5. Intellectual Property Rights
All content on dekowish.in, including text, images, logos, graphics, designs, and layout, is the intellectual property of Dekowish and is protected under applicable copyright and trademark laws.
You may not copy, reproduce, modify, or distribute any material from our website without our written consent.
Unauthorized use of our intellectual property may result in legal action.
6. Third-Party Links
Our website may contain links to external or third-party websites for your convenience.
Dekowish has no control over these websites and is not responsible for their content, policies, or practices.
We recommend reviewing their respective Terms and Privacy Policies before engaging with them.
7. Limitation of Liability
Dekowish strives to ensure accuracy and reliability of information on this website, but we make no warranties or representations regarding its completeness, accuracy, or availability.
To the fullest extent permitted by law, Dekowish will not be liable for any:
- Direct, indirect, or consequential losses or damages
- Data or profit loss arising from your use of our website or services
You acknowledge that your use of the website is entirely at your own risk.
8. Warranty and Service Disclaimer
While Dekowish ensures top-quality design and execution, all materials, furnishings, or installations provided by third-party vendors or manufacturers are subject to their individual warranties.
Dekowish is not responsible for damage, defects, or delays caused by third-party suppliers or unforeseen circumstances (e.g., material shortages, weather, or government restrictions).
9. User Responsibilities
By using our services or submitting project details, you agree that:
- All information you provide is accurate and complete.
- You will cooperate during project execution and approvals.
- You will not hold Dekowish responsible for any changes requested after project finalization that affect cost or timelines.
10. Privacy Policy
Your use of this website is also governed by our Privacy Policy, which explains how we collect and handle your personal data.
By using this website, you consent to such processing and warrant that all data you provide is accurate.
11. Termination of Access
Dekowish reserves the right to restrict or terminate your access to the website at any time, without prior notice, if we believe you have violated these Terms or engaged in any unlawful activity.
12. Changes to These Terms
Dekowish reserves the right to update or modify these Terms & Conditions at any time without prior notice.
All updates will be effective immediately upon posting on this page. Please review this page periodically to stay informed.
13. Governing Law
These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India, and any disputes shall be subject to the exclusive jurisdiction of the courts in Kolkata, West Bengal.
14. Contact Us
For any questions, concerns, or clarifications regarding these Terms & Conditions, please contact us at:
Dekowish
Kolkata, West Bengal, India
📧 Email: info@dekowish.in
🌐 Website: https://dekowish.in